Tenders

Main Contractor for the Blocks 1, 2, 3, 4, 5, 7, 10, 11, Site: Roof Works - Roof , Gutter & Internal Gutter + Roof Parts & AC Mount at Rosehill Intermediate School

Board of Trustees - Approve by BoT - ie. School Principal

This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Rosehill Intermediate School (the School) – Blocks 1, 2, 3, 4, 5, 7, 10, 11, Site: Roof Works – Roof, Gutter & Internal Gutter + Roof Parts & AC Mount Replacement – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks 12, 14: Wall Covering Replacement + Carpet Replacement at St Thomas School

Board of Trustees - Approve by BoT - ie. School Principal

This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for St Thomas School (the School) – Blocks 12, 14: Wall Covering Replacement + Carpet Replacement – Main Building Contractor (the Contract Works).

Main Contractor for the Block 4: Food Technology Repurposing at Rosehill Intermediate School

Board of Trustees - Approve by BoT - ie. School Principal

This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Rosehill Intermediate School (the School) – Block 4: Food Technology Repurposing – Main Building Contractor (the Contract Works).

Main Contractor for the Block 14: Intumescent Paint at St Thomas School

Board of Trustees - Approve by BoT - ie. School Principal

This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for St Thomas School (the School) – Block 14: Intumescent Paint – Main Building Contractor (the Contract Works).

Main Contractor for the Block 13: Food Tech Upgrade at St Thomas School

Board of Trustees - Approve by BoT - ie. School Principal

This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for St Thomas School (the School) – Block 13: Food Tech Upgrade – Main Building Contractor (the Contract Works).

Confocal Microscope

AG Science

New Zealand Institute for Bioeconomy Science Limited (BSI) seeks proposals for the supply, installation, commissioning, training and ongoing support of a research-grade confocal laser scanning microscope system to replace the ageing Olympus FV10i confocal microscope currently located at the Grasslands campus, Palmerston North. The new system will provide a shared research capability supporting plant-microbe interactions, plant pathology, microbiology, biotechnology, biosecurity and related biological sciences.

PNCC - 26_047 - Milson Line Water Reservoir Design and Build

Procurement

Palmerston North City Council (PNCC) invites proposals from qualified and experienced contractors for the design and construction of a new 2,500 m³ potable water storage reservoir at 230 Milson Line, Palmerston North. The Design and Build contract includes detailed design, investigations, consenting, construction, testing and commissioning, as outlined in the RFP and Technical Requirements. Interested suppliers are invited to submit their proposals through GETS by the specified closing date.

TKKM Rāwhiti Roa – Site: Drainage Works – Main Construction Contractor

Board of Trustees - Approve by BoT - ie. School Principal

The outcome sought from this procurement is the securing of the services of a suitably qualified and experienced main contractor to undertake the proposed Site: drainage works. The Kura’s original 5YA project scope included a drainage works design project. The system has had urgent remediation works undertaken already and the design of the new drainage system is complete. Due to the location of the proposed works and potential for disruption of the Kura’s operations, the contract works must be delivered during school holidays. The proposed scope includes the replacement of existing concrete paving to direct surface water towards new overland flow paths between Blocks 2, 3 & 5. The existing covered way path currently acts like a dam preventing surface water to flow through the natural flow path, so grated channels are proposed to allow water to escape when the surface flow exceeds the capacity of the existing catchpit. Additional ground contouring is proposed to deflect surface water from the area and instead direct to an existing adjacent catchpit and drainage network. Additionally, there are several areas of replacement drainage works required following a recent CCTV of the existing drains at the Kura. There is also some remedial wastewater drainage required, including the installation of new access chambers to resolve a sharp bend in the existing WW drainage infrastructure that has a tendency to block regularly.

RFT for Main Flooring Contractor for Blocks A & B Floor and Wall Coverings at Whangarei Girls High School

Board of Trustees - Approve by BoT - ie. School Principal

i. This project will undertake lifecycle replacement of floor and wall coverings throughout Block A and B.

RFT for Main Contractor for Drainage Works at Parua Bay School

Board of Trustees - Approve by BoT - ie. School Principal

The school is situated on the side of a hill and suffers from substantial water run-off through the carparks to the school and playcentre. CCTV investigations found the existing underground stormwater system and outlet from the school is too small and it regularly gets inundated. The gravel carpark to the playcentre has no existing drainage and it is continually being eroded by the water coming off the road reserve and school carpark above. The playcentre requires drainage and a concrete surface to prevent this from happening. The additional water capture will add more capacity to what an undersized stormwater network is already. Therefore, this must be upgraded at the same time as the playcentre carpark works.

Main Contractor for P: Pavilion Changing Rooms Refurbishment at Kelston Boys High School

Board of Trustees - Approve by BoT - ie. School Principal

Main Building Contractor for H O Student Toilets Refurbisment at Tahatai Coast School

Board of Trustees - Approve by BoT - ie. School Principal

To seek a main building contractor to carry out the refurbishment of the students toilets in Blocks H & O in poor condition. Including flooring, hardware and sanitary ware replacement, supply and provision of ventiallation, new partitions, lighting upgrade, hot water installation and wet linings installation.

MRGS Roofing Works – MCL Centre, Swimming Pool Changing Rooms, Uniform Shop and Blocks 3, 4 and 8 – Roof Replacement and Roof Remedial Works

Board of Trustees - Approve by BoT - ie. School Principal

English Medium Writing Workbook for Years 4 and 5

Te Poutahu Curriculum Centre

As part of the government’s budget announcement for 2026, funding has been set aside to provide Writing Workbooks for learners in Years 4 and 5 (approximately 130,000 students), for the next four financial years (assuming funding is retained). These Workbooks will help learners build strong foundations in fluent writing. Designed for flexible use across different subjects, they will support learners to revisit key concepts and practise independently as their confidence develops. They will help lift achievement by giving all learners consistent, easy-to-use support that helps build writing stamina and reinforce key skills. This RFP relates to the purchase of Writing Workbooks for learners in Years 4 and 5, with accompanying Teacher Support Materials (TSM), that are aligned with the New Zealand Curriculum (NZC) via an open market RFP issued on the Government Electronic Tender System (GETS). We are aware that many of the current offerings in the market are not aligned to the NZC and this means that suitable Workbooks and TSM are not readily available “off the shelf” and will need to be created. Therefore, we will consider applications based on either a completed Workbook or a representative chapter and exercises – in this case persuasive writing. The Ministry is interested in physical Writing Workbooks, printed by either the respondent or by our print provider, that are support by TSM, either in electronic or physical format. If Workbooks are printed by the Successful Respondent, the Ministry is seeking resources that can be provided in quantities of 1,000, and delivered to our distributor, at an average cost of $30.00 or less per Workbook. As a result of this procurement, the Ministry will create a list of up to three (3) Writing Workbooks for each Year group (i.e. up to 6 Writing Workbooks) that schools can select from. No minimum commitment to purchase will be given by the Ministry. Ongoing purchases will be made during purchasing windows, with suppliers being asked

RFP-Health NZ Northern Region Panel for Suppliers of Building Management Services (BMS) Projects and Maintenance Services

Northern Region

Health New Zealand – Northern Region (the Principal) is seeking to appoint a Panel of suitably qualified and experienced Suppliers of BMS Projects and Maintenance Services for its Planned Preventative Maintenance, Reactive Maintenance, and Projects requirements. The Principal consists of: • Auckland – its hospital campuses and community facilities; • Counties Manukau – its hospital campuses and community facilities; • Northland – its hospital campuses and community facilities ; and • Waitematā – its hospital campuses and community facilities. The Principal owns and operates facilities associated with delivering health and disability services and is responsible for the repair and maintenance of these facilities. These hospital campuses and community facilities are operational 24/7, shutdowns of services (both utilities and clinical) need to be carefully planned and considered to minimise impacts on patients and staff. Note: The Principal is undertaking this procurement on behalf of all Health New Zealand’s Northen Region hospitals and their community facilities. A Supplier must successfully proceed through all procurement phases and subsequent contract negotiations to be a panel member. Only suppliers on the panels will be able to provide in-scope services to the Northern Region hospitals. Refer to RFP documents for further details.

Hillcrest High School Design and build contractor for new sports canopy type building RoI

Board of Trustees - Approve by BoT - ie. School Principal

This opportunity is for a design and build contractor with experience and capability to undertake the design and build of a proposed new sports canopy. The canopy is not proposed as being a tensioned PVC type barrel rolled structure commonly referred to as a COLA but rather is a anticipated to be of more rigid construction but also not a 'building' like a gymnasium. The canopy will not be full weatherproof however is expected to allow for all year round undercover use for various sports.

ODC Contract 288: Waiotahe Bluffs Detour Improvements Localised Widening Works 2026

Opotiki District Council

Waiotahe Valley Back Road, Verrall Road and Paerata Ridge Road together form the detour route used when the Waiotahe Bluffs section of State Highway 2 is unavailable. When the detour is in operation the route carries diverted state highway traffic, including heavy freight, on a rural road network formed for local access. Verrall Road normally carries approximately 80 vehicles per day and Waiotahe Valley Back Road approximately 93. WSP’s Waiotahe Bluffs Detour Improvement Scope (WSP ref 2-34005.C2) identified substandard carriageway width through curves and constrained sections of the route. The objective of this contract is to widen those sections to a carriageway width that safely accommodates diverted state highway traffic, including two heavy vehicles passing, and to improve sightlines through the curves and at the Verrall Road / Paerata Ridge Road intersection. The Ōpōtiki District Council has a quality driven approach to its construction projects. In keeping with this philosophy, Contractors are expected to achieve the highest standard of performance on all aspects of this project. In particular, the Contractor shall pay attention to actively managing Temporary Traffic Management on a route that may become a live state highway detour at short notice, and to notifying the public and keeping residents and landowners informed of intended works.

Pacific Homework and Tutoring Initiative

Te Mahau Education Services

The procurement will establish contractual arrangements with providers that can deliver high-quality, culturally responsive tutoring services which support Pacific learners to improve literacy and numeracy achievement, strengthen engagement in learning, and increase preparedness for future educational pathways. The Pacific Homework and Tutoring Initiative is designed to provide supplementary educational support in addition to learning taking place within schools. Services are intended to assist Pacific learners who require additional support to strengthen their achievement in the literacy and numeracy co-requisite examinations. This service will be available to approximately 1150 ākonga in 17 schools across the Auckland region where Pacific learners comprise at least 50% of the years 9 and 10 student population. To register for the supplier briefing please email jacky.doonan@education.govt.nz

Water Mains Resilience Phase Three

Manukau Institute of Technology and Unitec

The Buyer requires a suitably qualified contractor to deliver the Phase three Water Mains Resilience works at the Unitec Mt Albert Campus. The works comprise targeted renewal, replacement, modification and installation of water infrastructure, together with associated civil works, testing, commissioning, reinstatement, and as-built documentation. The works are divided into four Work Packages (WP01–WP04), which define the specific scope and requirements. The successful Respondent will be responsible for providing a complete, end-to-end solution, including all planning, coordination, resources, procurement, construction, and project close-out necessary to deliver the works from commencement through to final handover.

Stratford Primary School Main Contract Works – Relocation of Wharenui & Demolition Block F RFT

Ministry of Education - School Infrastructure

Block F at Stratford Primary School was identified with weathertightness issues in 2016 and originally scoped for remediation under the Taranaki Cluster but the work had to be paused due to insufficient funding being available. The remediation of Block F was revisited in 2023, with a preliminary design completed in May of that year. The extensive nature of the required remediation due to the modulock construction and the lack of cost advantages meant the scope was revised with classroom replacement being recommended instead. The new scope agreed in 2025 includes: o Demolition of 3TS and Wharenui (1TS) in Block F o Refurbish, relocate, and convert Classroom 20 (K2 reference Classroom 1) into new Wharenui (1TS) o General siteworks, infrastructure, and sandpit relocation

RIV_2600611 Rangitata/Rakitata River Flood Resilience – Groyne Rockwork Reinstatement

Field Services

Canterbury Regional Council (Environment Canterbury) (the Council) has a statutory function under the Soil Conservation and Rivers Control Act 1941 to manage land use within the region to prevent and mitigate damage caused by floods and erosion (see s126 of the Act). The Council is seeking responses to this Request for Proposal from suitably experienced contractors to undertake construction of new groyne structures on the true right bank of the Rangitata/Rakitata River, below the Arundel bridge. This contract involves the construction of four groynes. Details of works required are included in the Specifications in Part C and Construction Plans in Appendix 3. Note the number of groynes constructed may vary between two and four depending on tender prices as the project has a fixed budget for these improvements. Environment Canterbury will agree to the final scope of work with the selected contractor prior finalising contract documents. The work sites for the groynes are located on riverbed and in river berm. Access to the work sites will be via the Rangitata South Irrigation Limited (RSIL) pond access road, property owned by Rangitata Water Limited. All necessary agreements are in place with the landowner with regard to this work. Works will require the clearance of berm vegetation, removal of existing groynes, and clearance of any unsuitable material from the works area, prior to the construction of the four new groynes. It is possible that Rangitata River braids will be located near or within the proposed works site. The Contractor may therefore need to undertake diversion works to ensure that the groyne construction can proceed in the dry. The works will require the carting and placing of approximately 5500 tonne of rock from a RSIL stockpile adjacent to the site to form the new groynes. A further 9000 tonne of rock will need to be procured and imported to the site to form the further groynes. Rock from the existing groynes slated for removal may be suitable[JN1.1]

Main Contractor - ROI - Concrete Retaining Wall Replacement at Pakuranga College

Board of Trustees - Approve by BoT - ie. School Principal

The project comprises the full replacement of the existing approximately 90 metre crib retaining wall at Pakuranga College, Pigeon Mountain Road, Half Moon Bay, Auckland. The wall was constructed in the 1970s and has experienced partial failures, displacement, rotation, loss of retained material, voiding and cracking. The current concept is a reinforced-concrete soldier-pile retaining wall constructed behind the existing crib wall. The outcome sought is a permanent retaining solution that replaces the failed crib wall, supports the retained bank, manages their construction risks to adjacent school buildings and occupants.

Доставка на фабрично изработени абонатни станции за ЕВН България Топлофикация ЕАД

ЕВН БЪЛГАРИЯ ТОПЛОФИКАЦИЯ ЕАД

Доставка на фабрично изработени абонатни станции за ЕВН България Топлофикация ЕАД. Доставка на напълно сглобени, тествани, с функциониращо окабеляване за безпроблемно и ефективно инсталиране на нови абонатни станции (АС) до помещенията, предвидени за ситуирането им.

„Следгаранционно сервизно и техническо обслужване, профилактика, диагностика и ремонт на мотори превозни средства, включително доставка на резервни части и консумативи за тях, собственост на „ЮЦДП” – Смолян за срок от 24 месеца"

ТЕРИТОРИАЛНО ПОДЕЛЕНИЕ "ДЪРЖАВНО ГОРСКО СТОПАНСТВО - СМОЛЯН"

Настоящата поръчка включва следните дейности: следгаранционно сервизно и техническо обслужване, профилактика, диагностика, текущ и основен ремонт, включително доставка и подмяна на авточасти, детайли, материали и консумативи за моторни превозни средства, подробно описани в Техническата спецификация Приложение № 2 част от документацията за участие.